Section 36.10.125. Enforcement.

   (a) The attorney general shall, when requested by the Department of Labor and Workforce Development, enforce the provisions of this chapter.  The attorney general may obtain a court order prohibiting a contractor or subcontractor violating this chapter from continuing to work on existing public construction contracts of the state or a political subdivision of the state.  The state or political subdivision of the state may prosecute the work to completion by contract or otherwise, and the contractor or subcontractor and the sureties of the contractor or subcontractor are liable for excess costs for completing the work.
   (b) A private person is entitled to bring an action in the superior court to enforce the provisions of this chapter if that private person first gives at least 20 days notice to the commissioner of labor and workforce development.  The notice must set out
        (1) the intent of the private person to bring an action under this subsection;
        (2) the specific violation complained of; and
        (3) the name of the person accused of the violation.
   (c) [See delayed amendment note]. =ro In an action brought under (b) of this section, the court may, in its discretion, order denial of state community assistance, revenue sharing, or public school funding, forfeiture of office or position, or injunctive or other relief. If the court finds for the plaintiff in an action brought under (b) of this section, it may award the plaintiff an amount equal to the actual costs and attorney fees incurred by the plaintiff.

Notes

Recent Bills that will modify this

SB 210 COMMUNITY REVENUE SHARING/ASSISTANCE

Implemented As

8 AAC 30.110

History

(Sec. 13 ch 142 SLA 1972; am Sec. 1 ch 183 SLA 1976; am Sec. 36 ch 83 SLA 1998; am Sec. 14 ch 44 SLA 2016)